HomeMy WebLinkAboutItem 05 Approval of ITB #20-003 Landscaping Improvements in the Medians on SR 50 (W. Colonial Drive Between SR 429 and Good Homes Road) to SSS Down to Earth OPCO II, LLC ocoee
florida
AGENDA ITEM COVER SHEET
Meeting Date: February 18, 2020
Item #:
Reviewed By:
Contact Name: Ginger Corless, CRA Department Director: Craig Shadrix, Assistant City
Administrator Manager rizA
Contact Number: 407-905-3100 ext. 1028 City Manager: Robert Fra
Subject: Contract Assignment of ITB#20-003 Landscaping Improvements in theedians on SR 50(W.
Colonial Drive between SR 429 and Good Homes Road)to SSS Down to Earth OPCO II, LLC.
Background Summary:
The award recommendation for the above-referenced bid was submitted by Staff after FDOT's review and
approval to proceed with the recommendation. On January 21, 2020, under Agenda item No. 4, City
Commission awarded ITB#20-003 to SSS Down to Earth OPCO, LLC. The Contract for Construction was
prepared naming SSS Down to Earth OPCO, LLC and sent out for signature.
On January 28th, the City was informed by the contractor that they had inadvertently submitted documents
naming the incorrect company. For municipal projects, the contractor uses the name and federal identification
number for SSS Down to Earth OPCO II, LLC and not SSS Down to Earth OPCO, LLC.
Staff sent the issue to Ms. Crosby-Collier, Shuffield Lowman, for her review and opinion of action. Based on her
direction, SSS Down to Earth OPCO, LLC has signed the original contract and submitted the attached
document for the City to execute requesting the Contract be assigned to SSS Down to Earth OPCO II, LLC. The
attached document recognizes that SSS Down to Earth OPCO II, LLC is responsible for and will comply with all
requirements and specifications of the contract documents and has the full ability to perform all functions. The
assignment form stipulates that the information provided by the bidder, including references, resumes, and
similar projects completed, is the same for both SSS Down to Earth OPCO, LLC and SSS Down to Earth OPCO
II, LLC.
Issue:
Approval of Assignment of the Construction Contract for ITB#20-003 Landscaping Improvements in the Medians
on SR 50 to SSS Down to Earth OPCO II, LLC.
Recommendations:
Staff recommends approval of the Assignment of the Construction Contract for ITB#20-003 Landscaping
Improvments in the Medians on SR 50 to SSS Down to Earth OPCO II, LLC.
Attachments:
Assignment of Contract Form
Construction Contract
1
Financial Impact:
There is no financial impact to the City for this contract assignment.
Type of Item: (please mark with an "x")
❑ Public Hearing For Clerk's Dept Use:
❑ Ordinance First Reading ;211 Consent Agenda
❑ Ordinance Second Reading 0 Public Hearing
❑ Resolution 0 Regular Agenda
® Commission Approval
O Discussion& Direction
❑ Original Document/Contract Attached for Execution by City Clerk
O Original Document/Contract Held by Department for Execution
Reviewed by City Attorney
Reviewed by Finance Dept. C.tx
Reviewed by
2
4,04
ocoee
f i o r i d a January 23,2020
Mayor
Rusty Johnson Michael Mosler II, President
Commissioners SSS Down to Earth OPOC,LLC
Larry Brinson,Sr 2701 Maitland Center Parkway, Suite 200
District 1 Maitland,FL 32751
Rosemary Wilsen NOTICE OF AWARD FOR ITB#20-003 LANDSCAPE IMPROVEMENTS IN THE
District 2
MEDIANS ON SR 50 BETWEEN SR 429 AND GOOD HOMES ROAD
Richard Firstner
District 3 Notice is hereby given that at the January 21,2020,City Commission meeting your company
George Oliver III was awarded the contract to provide construction services related to ITB#20-003 Landscape
District 4 Improvements in the Medians on SR 50 between SR 429 and Good Homes Road.
City Manager In accordance with the terms of the Invitation to Bid,you must now execute the contract for
Robert D.Frank the work(two copies enclosed).An Officer of the company must sign the contract;or provide
a letter signed by an Officer of the company authorizing a certain employee of the company
to sign the contract. You must also provide the required performance and payment bond on
the forms provided in the bid documents, insurance certificate naming the City as additional
insured, and endorsements. Return all contract documents to my attention within ten (10)
business days.The City will date and return a fully executed copy of the contract to you once
executed,along with your original copy of the dated bonds. Under the terms of the Invitation
to Bid, this Notice of Award shall be rescinded if you do not timely provide the required
contract documents.
Effective October 1,2012,revisions to State of Florida Statute 255.05 will apply to this
contract. Once you receive the fully executed contract and dated bonds from the City,
you will need to record the performance and payment bonds with Orange County. You
are required to provide the City with a certified copy of the recorded bonds before the
City can issue the Notice to Proceed or make any payment for the project.
Additionally, please contact Ginger Corless, AICP, CPRP at (407) 905-3100 ext. 1028 to
schedule the pre-construction meeting for this project. The certified copy of the recorded
bonds will need to be provided prior to or at the pre-construction meeting. Completion dates
will be established at the pre-construction meeting.Work shall begin pursuant to the effective
date established by the Notice to Proceed
The C. ;. looking forward to working with your company on this project.
Regar..
/ ,/"
Shannon '*pper
. g Technician
cc: Ginger Corless,Deputy Development Services Director/CRA Administrator
City of Ocoee • 150 N Lakeshore Drive •Ocoee, Florida 34761
Phone: (407) 905-3100•www.ocoee.org
r DOWN TO
EARTH
LANDSCAPE & IRRIGATION
February 4, 2020
City of Ocoee
150 N Lakeshore Drive
Ocoee, FL 34761
ASSIGNMENT REQUEST
On made this day February 04, 2020, SSS Down To Earth OPCO, LLC is requesting the City of
Ocoee reassign the Contract for ITB#20-003 Landscape Improvements in the Medians on SR 50
between SR 50 between SR 429 and Good Homes Road,to SSS Down To Earth OPCO II,LLC.
WHEREAS, SSS Down To Earth OPCO, LLC,entered into a Contract with the City of Ocoee,
included as an attachment to this Agreement,namely ITB#20-003 Landscape Improvements in
the Medians on SR 50 between SR 50 between SR 429 and Good Homes Road.
1. SSS Down To Earth OPCO,LLC agree that the City of Ocoee shall assign all obligations,
responsibilities,and duties, in and to the Contract,to SSS Down To Earth OPCO II, LLC,who
has the ability to perform all functions the same as SSS Down To Earth OPCO,LLC.
2. SSS Down To Earth OPCO II,LLC hereby accepts the assignment of all obligation's
responsibilities and provisions under the Contract.
SSS Down To Earth OPCO LLC SSS Down To Earth OPCO II,LLC
BY: 'ri I� BY: AAA
,�y r (S1�'�/
ITS: , o ITS: /fr;-o. ��
City of Ocoee
BY:
ITS:
CONTRACT FOR CONSTRUCTION
THIS AGREEMENT is dated as of the day of in the year 2020 by and
between the City of Ocoee, a Florida municipal corporation, hereinafter called Owner, and
SSS Down to Earth OPCO, LLC,hereinafter called Contractor.
Owner and Contractor, in consideration of the mutual covenants hereinafter set forth, agree as follows:
ARTICLE 1. WORK
Contractor shall complete all work as specified or indicated in the Contract Documents. The work is generally
described as follows:
ITB#20-003
LANDSCAPING IMPROVEMENTS
IN THE MEDIANS ON
SR 50 (W. COLONIAL DRIVE)
BETWEEN SR 429 AND GOOD HOMES ROAD
FDOT FM 443786-1-58-01/02
Scope of Work
Pursuant to the Joint Participation Agreement between the State of Florida Department of Transportation"FDOT"
and the City of Ocoee, the proposed Contract will be for the labor, supervision, materials, equipment, supplies
and incidentals for installing landscaping within the right-of-way of the medians on SR 50 between SR 429 and
Good Homes Road (Section 75050000: Milepost 6.075 to Milepost 9.338), in the City of Ocoee, as listed under
the "Scope of Work/Bid Form," per the plans/specifications provided by CPH, Inc. section of Invitation to Bid
#20-003.All work for this contract shall conform to the applicable technical specifications of Florida Department
of Transportation(FDOT) "Standard Specifications for Road and Bridge Construction"July 2019.All warranties
on any product or material used in the construction of this project shall be in favor of the City.
In accordance with the plans and specifications prepared by CPH for the SR 50 Landscaping Improvements in
the Medians,the proposed contractor will:
• Prepare and submit for approval a detailed schedule.
• Properly prepare all planting areas by removing the existing sod and any and all debris, adding soil
amendments and adjusting grade for proper planting.
• Purchase all materials, equipment and supplies required and install the irrigation system for each median
as specified.
• Purchase all trees,palms, shrubs and groundcover for the project and install them as specified.
• Stake all trees and palms according the plans and specifications.
• Fertilize all trees,palms, shrubs and groundcover.
• Purchase, supply and spread organic mulch as specified.
• Provide and establish proper Maintenance of Traffic(MOT)as needed.
• Provide the City with copies of any and all executed contracts with subcontractors.
• The project must be completed and the as-builts and all invoices submitted by December 16, 2020.
As-built plans must be prepared following the FDOT Construction Project Administration Manual,
Chapter 5.12.
ITB#20-003 Landscaping Improvements Medians SR 50 between SR 429&Good Homes Page I of 8
• Provide maintenance of the median landscaping for the warranty period of one year. Maintenance will
include mowing and maintenance on the trees,palms, shrubs, and groundcover on a weekly basis during
May through September and biweekly October-April.
• Comply with FDOT's attached special provisions that apply to this project.
• All warranties on any product or material used in construction of this project shall be in favor of the City.
ARTICLE 2. ARCHITECT AND ENGINEER
The Project has been designed by CPH, Inc.; however, the City's Deputy Development Services Director/CRA
Administrator or her designee is to act as Owner's representative, assume all duties and responsibilities of the
project engineer,and have the rights and authority assigned to Engineer in the Contract Documents in connection
with completion of the work.
ARTICLE 1 CONTRACT TIME
3.1 The work shall be substantially complete (all work complete except for the placement of permanent
pavement markings on all final asphaltic concrete surfaces) within one hundred twenty (120) calendar
days. The entire work shall be complete and ready for its intended use, including final dressing and
cleanup,within one hundred fifty(150)calendar days.All time periods begin from the effective date of
the Notice to Proceed.
32 Placing of permanent pavement markings on all final asphaltic concrete surfaces, if applicable, shall not
be accomplished before thirty (30) calendar days have elapsed after placement of the final surfaces. The
charging of Contract Time will be suspended during the thirty(30)calendar-day period provided the work
is considered to be Substantially Complete, as provided in paragraph 3.1 above. The charging of Contract
Time will resume on the 31st day.
33 Contractor recognizes that time is of the essence of this Agreement and that Owner will suffer financial
loss if the work is not completed within the times specified in above,plus any extensions thereof allowed.
Contractor acknowledges that proving the actual loss and damages suffered by Owner if the work is not
completed on time is impracticable and not susceptible to exact calculation. Accordingly, instead of
requiring any such proof, Contractor agrees that as liquidated damages for delay (but not as a penalty)
Contractor shall pay Owner Two Hundred Dollars ($200.00) for each day that expires beyond the date
specified in paragraph 3.2 above for substantial completion Two Hundred Fifty Dollars($250.00)for each
day that expires beyond the date specified in paragraph 3.2 above for final completion(readiness for final
payment).
34 In addition to the liquidated damages,there shall be additional incidental damages paid by the Contractor
to the Owner for failure to timely complete the work. These may include, but not be limited to, delay
damage settlements or awards owed by Owner to others, inspection and engineering services, interest and
bond expense, delay penalties, fines or penalties imposed by regulatory agencies, contract damages, and
professional fees (including attorneys' fees)incurred by Owner in connection with Contractor's failure to
timely complete the work.
35 In addition to liquidated damages and incidental damages arising from Contractor's failure to perform the
work,Contractor may be required to repay Owner for the cost of corrective actions undertaken by Owner
to resolve construction defects. Such corrective actions include, but are not limited to, restoration of
damaged areas, clearing of reclaimed water customer facilities to remove construction
ITB#20-003 Landscaping Improvements Medians SR 50 between SR 429&Good Homes Page 2 of 8
debris, repair and replacement of damaged reclaimed water customer equipment,and emergency repairs
to the reclaimed water distribution system during construction.
ARTICLE 4. CONTRACT PRICE
4.1 Owner shall pay Contractor for performance of the work in accordance with the Contract Documents in
current funds at the lump sum or unit prices presented in the Bid Form: ONE MILLION TWO
HUNDRED EIGHTY-THREE THOUSAND NINETY-SIX DOLLARS AND NINETY-EIGHT
CENTS ($1.283.096.98,which is incorporated herein and made a part hereof by this reference.
4.2 The Contractor agrees that the Contract Price is a stipulated sum except with regard to those items in the
bid which are subject to unit prices and agrees to perform all of the work as described in the Contract
Documents, subject to additions and deductions by Change Order, and comply with the terms therein for
the Bid stated in the attached Bid Form.
ARTICLE 5. PAYMENT PROCEDURES
Contractor shall submit applications for payment. Applications for payment will be processed by Engineer.
5.1 Progress Payments. Owner shall make progress payments on account of the Contract Price on the basis of
Contractor's properly submitted and approved Applications for Payment, as recommended by Engineer,
not later than the Twenty-fifth (25th) business day after the date on which the properly submitted
Application for Payment is initially received by the Owner. All such progress payments will be on the
basis of the progress of the work measured by the Schedule of Values and in the case of Unit Price, work
based on the number of units completed and included in Contractor's qualifications submittals.
5.1.1 Progress payments will be made in an amount equal to the percentage indicated in Paragraph 5.1.2,
below, but, in each case, less the aggregate of payments previously made and less such amounts
as Engineer shall determine, or Owner may withhold.
5.12 Progress payments shall be equal to ninety percent (90%) of the value of work completed, and
ninety percent(90%) of the value of materials and equipment not incorporated into the work but
delivered and suitably stored and accompanied by documentation satisfactory to Owner with the
balance of the value of the work being retainage. However, when the work has reached the point
of being fifty percent(50%)complete,the retainage may not exceed five percent(5%)of the value
of the work completed.
5.2 Final Payment-Upon final completion and acceptance of the work,Owner shall pay Contractor an amount
sufficient to increase total payments to 100 percent of the Contract Price. However, not less than two
percent (2%) of the contract price shall be retained until Record Drawings, specifications, addenda,
modifications and shop drawings, including all manufacturers instructional and parts manuals, are
delivered to and accepted by the Engineer.
ARTICLE 6. INTEREST
All monies not paid when due shall bear interest at the rate of 3%simple interest per annum.
ITB#20-003 Landscaping Improvements Medians SR 50 between SR 429&Good Homes Page 3 of 8
ARTICLE 7. CONTRACTOR'S REPRESENTATIONS
In order to induce Owner to enter into this Agreement, Contractor makes the following representations:
7.1 Contractor has examined and carefully studied the Contract Documents (including the Addenda listed in
paragraph 8)and the other related data identified in the Bidding Documents including "technical data."
7.2 Contractor has visited the site and become familiar with and is satisfied as to the general, local and site
conditions that may affect cost,progress, performance and furnishings of the work.
7.3 Contractor is familiar with and is satisfied as to all federal, state, and local laws and regulations that may
affect cost,progress, performance, and furnishing of the work.
7.4 Contractor has carefully studied all reports of explorations and tests of subsurface conditions at or
contiguous to the site and all drawings of physical conditions in or relating to existing surface or
subsurface structures at or contiguous to the site (except Underground Facilities).
7.5 Contractor has obtained and carefully studied (or assumes responsibility for having done so) all such
additional supplementary examinations, investigations, explorations, tests, studies and data concerning
conditions(surface,subsurface and Underground Facilities)at or contiguous to the site or otherwise which
may affect costs, progress, performance or furnishing of the work or which relate to any aspect of the
means,methods,techniques,sequences and procedures of construction to be employed by Contractor and
safety precautions and programs incident thereto. Contractor does not consider that any additional
examinations, investigations, explorations, tests, studies or data are necessary for the performance and
furnishing of the work at the Contract Price, within the Contract Times and in accordance with the other
terms and conditions of the Contract Documents.
7.6 Contractor is aware of the general nature of work to be performed by Owner and others at the site that
relates to the work as indicated in the Contract Documents.
7.7 Contractor has correlated the information known to Contractor, information and observations obtained
from visits to the site, reports and drawings identified in the Contract Documents and all additional
examinations, investigations,explorations, tests, studies and data with the Contract Documents.
7.8 Contractor has given Engineer written notice of all conflicts, errors, ambiguities or discrepancies that
Contractor has discovered in the Contract Documents and the written resolution thereof by Engineer is
acceptable to Contractor, and the Contract Documents are generally sufficient to indicate and convey
understanding of all terms and conditions for performance and furnishing of the work.
7.9 Contractor shall perform work with a value of not less than fifty percent(50%)of the Contract Price with
his own forces. All subcontractors must be pre-approved by the City.
ARTICLE 8. CONTRACT DOCUMENTS
The Contract Documents,which comprise the entire agreement between Owner and Contractor concerning the
work,are attached to this Agreement,made a part hereof, and consist of the following:
8.1 This Scope of work Agreement.
ITB#20-003 Landscaping Improvements Medians SR 50 between SR 429&Good Homes Page 4 of 8
8.2 Exhibits to this Scope of work Agreement(if any).
8.3 FDOT Supplemental Specifications and Special Provisions and Requirements included in the ITB.
8.4 Performance Bond, Payment Bond and Certificates of Insurance.
8.5 Notice of Award and Notice to Proceed.
8.6 Bid Documents bearing the general title Invitation to Bid "ITB#20-003 Landscaping Improvements in
the Medians on SR 50 (W. Colonial Drive) between SR 429 and Good Homes Road, FDOT FM
443786-1-58-01/02",dated November 2019.
8.7 Drawings consisting of a cover sheet and the sheets bearing the following general title:
CITY OF OCOEE,FL
LANDSCAPING IMPROVEMENTS
IN THE MEDIANS ON
SR 50 (W. COLONIAL DRIVE)
BETWEEN SR 429 AND GOOD HOMES ROAD
FDOT FM 443786-1-58-01/02
8.8 Addenda numbers 1 to 2,inclusive.
8.9 Contractor's Bid.
8.10 Documentation submitted by Contractor prior to Notice of Award.
There are no Contract Documents other than those listed above in this Article 8.
ARTICLE 9. MISCELLANEOUS
9.1 No assignment by a party hereto of any rights under, or interests in, the Contract Documents will be
binding on another party hereto without the written consent of the party sought to be bound; and
specifically, but without limitation, moneys that may become due, and moneys that are due, may not be
assigned without such consent (except to the extent that the effect of this restriction may be limited by
law),and unless specifically stated to the contrary in any written consent to an assignment,no assignment
will release or discharge the assignor from any duty or responsibility under the Contract Documents.
Notwithstanding the foregoing,the Owner may assign this contract to the State of Florida or any political
subdivision, municipality, special district or authority thereof without Contractor's consent and without
recourse.
92 Owner and Contractor each binds himself, his partners, successors, assigns and legal representatives to
the other party hereto, his partners, successors, assigns, and legal representatives in respect to all
covenants, agreements, and obligations contained in the Contract Documents.
93 Chapter 558,Florida Statutes: The parties agree that the provisions of Chapter 558,Florida Statutes are
not applicable to this Agreement.
ITB#20-003 Landscaping Improvements Medians SR 50 between SR 429&Good Homes Page 5 of 8
94 Waiver of Jury Trial; Legal Costs. It is mutually agreed by and between the Contractor and Owner that
each of the parties do hereby waive trial by jury in any action,proceeding or claim which may be brought
by either of the parties hereto against the other on any matters concerning or arising out of this Agreement.
The parties further agree that the sole and exclusive venue for any action to enforce this agreement shall
be in The Circuit Court of the Ninth Judicial Circuit in and for Orange County,Florida.
95 Any provision or part of the Contract Documents held to be void or unenforceable under any Law or
Regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding
upon Owner and Contractor, who agree that the Contract Documents shall be reformed to replace such
stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to
expressing the intention of the stricken provision.
9.6 SCRUTINIZED COMPANIES: The Respondent certifies that the company is not participating in a
boycott of Israel. The Respondent certifies that the Respondent is not on the Scrutinized Companies that
Boycott Israel List,not on the Scrutinized Companies with Activities in Sudan List,not on the Scrutinized
Companies with activities in the Iran Petroleum Energy Sector List, or has been engaged in business
operations in Cuba or Syria, as those terms are used and defined in sections 287.135 and 215.473 of the
Florida Statutes. In the event that the Respondent is unable to provide such certification but still seeks to be
considered for award of this solicitation, the Respondent shall, on a separate piece of paper, clearly state that it is
on one or both of the Scrutinized Companies lists and shall furnish together with its proposal a duly executed written
explanation of the facts supporting any exception to the requirement for certification that it claims under Section
287.135 of the Florida Statutes. The Respondent agrees to cooperate fully with the City in any investigation
undertaken by the City to determine whether the claimed exception would be applicable. The City shall have the
right to terminate any contract resulting from this solicitation for default if the Respondent is found to have
submitted a false certification, or to have been placed on the Scrutinized Companies that Boycott Israel List,or to
have been placed on the Scrutinized Companies for Activities in Sudan List, or the Scrutinized Companies with
Activities in the Iran Petroleum Energy Sector List,or has been engaged in business operations in Cuba or Syria.
9.7 The Contractor and any subcontractors performing the work or providing services pursuant to the state
contract shall utilize the U.S. Department of Homeland Security's E-Verify system to verify the
employment eligibility of all new employees hired by the Contractor/subcontractor during the contract
term.
9S To the degree records are not exempt or confidential under Florida's Public Records law, Contractor
agrees to comply with Chapter 119, Florida Statutes, and particularly Section 119.0701, Florida Statutes,
relating to a contractor's obligation with regard to public records.
99 PUBLIC RECORDS COMPLIANCE
The City of Ocoee (City) is a public agency subject to Chapter 119, Florida Statutes. The Contractor agrees to
comply with Florida's Public Records Law. Specifically, the Contractor shall:
1. Keep and maintain public records required by the City to perform the service.
2. Upon request from the City's custodian of public records,provide the City with a copy of the requested records
or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost
provided in chapter 119, Florida Statutes, or as otherwise provided by law.
ITB#20-003 Landscaping Improvements Medians SR 50 between SR 429&Good Homes Page 6 of 8
3. Ensure that public records that are exempt or confidential and exempt from the public records disclosure
requirements are not disclosed except as authorized by law for the duration of the contract term and following
completion of the contract if the Contractor does not transfer the records to the City.
4. Upon completion of the contract, Contractor agrees to transfer at no cost to the City all public records in
possession of the Contractor or keep and maintain public records required by the City to perform the service.If
the Contractor transfers all public record to the City upon completion of the contract,the Contractor shall destroy
any duplicate public records that are exempt or confidential and exempt from public records disclosure
requirements. If the Contractor keeps and maintains public records upon completion of the contract, the
Contractor shall meet all applicable requirements for retaining public records. All records stored electronically
must be provided to the City, upon request from the City's custodian of public records, in a format that is
compatible with the information technology systems of the City.
5. A Contractor who fails to provide the public records to City within a reasonable time may be subject to penalties
under section 119.10, Florida Statutes.
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF
CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO
PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE
CUSTODIAN OF PUBLIC RECORDS AT 407-905-3100, EXTENSION 1022,
CCDL@ci.ocoee.fl.us, WITH AN OFFICE LOCATED AT 150 NORTH LAKESHORE
DRIVE, OCOEE, FLORIDA 34761.
ITB#20-003 Landscaping Improvements Medians SR 50 between SR 429&Good Homes Page 7 of 8
IN WITNESS WHEREOF, the parties hereto have signed this Agreement. All portions of the Contract
Documents have been signed or identified by Owner and Contractor or by Engineer on his behalf.
CONTRACTOR: SSS DOWN TO EARTH OPCO,LLC
BY:
PRINT NAME: ONCk-kIPk-L. C(1iOSl..tg. T�
TITLE: RCCA c\ \'}
WITNESSES:
NAME: Ky /� NAME: Xr 4 /L+IJ ►� "�
TITLE:E)# r"+4- .An"A .? s e' TITLE: QIUg C1 l MATT c
OWNER: CITY OF OCOEE,FLORIDA
ATTEST: APPROVED:
BY: BY:
Melanie Sibbitt,City Clerk Rusty Johnson, Mayor
(SEAL)
FOR USE AND RELIANCE ONLY BY APPROVED BY CITY OF OCOEE
THE CITY OF OCOEE, FLORIDA COMMISSION AT A MEETING HELD
APPROVED AS TO FORM AND LEGALITY on January 21,2020 under Agenda Item 4.
this day of , 2020
SHUFFIELD, LOWMAN&WILSON,P.A.
BY:
Scott A_Cookson,City Attorney
END OF SECTION
ITB#20-003 Landscaping Improvements Medians SR 50 between SR 429&Good Homes Page 8 of 8